Terms and Conditions
1. Acceptance
1.1 This Agreement is between CourseWizz Ltd & its successors and assignees, (referred to as “we”, “us” or “our”), and the Client described in the form completed on our Website (referred to as “you” or “your”), and collectively the Parties.
1.2 You have requested specific services, described on and able to be ordered via our Website (Services). You accept these Terms by: (a) ticking the online acceptance box (b) confirming by email that you accept the Terms (c) instructing us to proceed with the Services (d) making part or full payment for the Services, set out in our tax invoice to you (Invoice).
1.3 You agree that these Terms form the agreement under which we will supply Services to you. Please read these Terms carefully. Please contact us if you have any questions. Purchasing Services from us indicates that you have had sufficient opportunity to read these Terms and contact us if needed, that you have read, accepted and will comply with these Terms, and that you are 18 years or older, or have the consent of a legal guardian who is 18 years or older. You must not order services from us if you are under 18 years of age or do not have the consent of a legal guardian who is 18 years or older. If you do not agree to these Terms, you should not purchase from us.
1.4 We will not commence performing our Services until you have paid the Fees or issued us with a valid Purchase Order for trainings required for a group of 10 or more candidates
2. Services
2.1 We agree to perform the Services set out on our Website with due care and skill.
2.2 We may provide the Services to you using our employees, contractors and third party providers and they are included in these Terms.
2.3 Our Services cover the scope on our Website.
3. Price, Invoicing and Payment
3.1 You agree to pay us the amounts set out on our Website, for the chosen Services (Price). All amounts are stated in the currency specified on our Website. All purchase prices exclude taxes (where applicable). You will be issued with a ticket and receipt of payment by email immediately following full payment of the fees
3.2 You agree to pay our Invoices within the Invoice Terms. If an Invoice is unpaid for more than 14 days we will cease to provide Services to you, until we receive payment of the Invoice.
3.3 If our Website states that the Fees and Expenses are an estimate only, you acknowledge that the final Fees and Expenses may be more or less than the estimated amounts. We will endeavour to inform you of any material variation as it becomes apparent.
3.4 Our pricing structure, payment methods and these Terms may be amended from time to time at our discretion. The pricing changes will apply to you for services provided to you after the date of the change. All other changes will apply from the date that the amended or new Terms are posted on our website or are provided to you, whichever is earlier.
4. Your Obligations and Warranties
4.1 You warrant that you will not canvass, employ, induce or attempt to employ, induce, solicit or entice away from us, any employee or contractor that was employed by or contracted to us during the term that we provide Services to you or the prior twelve (12) month period.
4.2 You warrant that throughout the term of this Agreement that:
(a) There are no legal restrictions preventing you from agreeing to the Terms;
(b) You will co-operate with us and provide us with information and comply with requirements in a timely manner, as requested by us from time to time, that are reasonably necessary to enable us to perform the Services;
(c) The information you provide to us is true, correct and complete;
(d) You will not infringe any third-party rights in working with us and receiving the Services;
(e) You will inform us if you have reasonable concerns relating to our provision of Services under the Terms, with the aim that we and you will use all reasonable efforts to resolve the concerns;
(f) You are responsible for obtaining any consents, licences and permissions from other parties necessary for the services to be provided, at your cost, and for providing us with the necessary consents, licences and permissions;
(g) You consent to the use of your name and Intellectual Property in relation to the Services in a way which may identify you
4.3 If you wish to transfer to a different Course, you must provide us with written notice no less than 7 days prior to the date of your original chosen Course.
5. Our Intellectual Property
5.1 The work and materials that is provided to you in carrying out the Services contains material which is owned by Amazon Web Services and we do not claim any credit for the same.
5.2 You agree that, as between you and us, we own all Intellectual Property rights in our Materials, and that nothing in these Terms constitutes a transfer of any Intellectual Property ownership rights in our Materials, except as stated in these Terms or with our written permission.
5.3 Your use of our Materials does not grant you a licence, or act as a right of use, any of the Intellectual Property in the Materials, whether registered or unregistered, except as stated in these Terms or with our written permission.
5.4 You must not breach our copyright or Intellectual Property rights by, including but not limited to:
(a) altering or modifying any of the Materials;
(b) creating derivative works from the Materials; or
(c) using our Materials for commercial purposes such as on sale to third parties.
6. Your Intellectual Property
6.1 You agree to provide information including Intellectual Property to us to enable us to provide the Services. You:
(a) warrant that you have all necessary rights to provide the Intellectual Property to us;
(b) grant us a perpetual, non-exclusive, royalty–free, irrevocable, worldwide and transferable right and licence to use the Intellectual Property in any way we require to provide the Services to you;© consent to any act or omission which would otherwise constitute an infringement of your Moral Rights.
7. Confidental Information
7.1 We, including our employees and contractors, agree not to disclose your Confidential Information to any third party; to use all reasonable endeavours to protect Confidential Information from any unauthorised disclosure; only to use the Confidential Information for the purpose for which it was disclosed by you and not for any other purpose.
7.2 You, including your employees and contractors, agree not to disclose our Confidential Information to any third party; to use all reasonable endeavours to protect Confidential Information from any unauthorised disclosure; and only to use the Confidential Information for the purpose for which it was disclosed or provided by us to you, and not for any other purpose.
7.3 These obligations do not apply to Confidential Information that:
(a) is authorised to be disclosed;
(b) is in the public domain and/or is no longer confidential, except because of breach of these Terms;
(c) is received from a third party, except where there has been a breach of confidence; or
(d) must be disclosed by law or by a regulatory authority including under subpoena.
7.4 The obligations under this clause will survive termination of these Terms.
8. Feedback and Dispute Resolution
8.1 Your feedback is important to us. We seek to resolve your concerns quickly and effectively. If you have any feedback or questions about our Services, please contact us at info@coursewizz.com
8.2 If there is a dispute between the Parties in relation to these Terms, the Parties agree to the following dispute resolution procedure:
(a) The complainant must tell the respondent in writing, the nature of the dispute, what outcome the complainant wants and what action the complainant thinks will settle the dispute. The Parties agree to meet in good faith to seek to resolve the dispute by agreement between them (Initial Meeting).
(b) If the Parties cannot agree how to resolve the dispute at the Initial Meeting, any Party may refer the matter to a mediator. If the parties cannot agree on who the mediator should be. The Parties must attend the mediation in good faith, to seek to resolve the dispute.
8.3 Any attempts made by the Parties to resolve a dispute pursuant to this clause are without prejudice to other rights or entitlements of the Parties under these Terms, by law or in equity.
9. Consumer Law, Limitation of Liability and Disclaimers
9.1 UK Consumer Rights Act: Certain legislation including the UK Consumer Rights Act 2015, and similar consumer protection laws and regulations may confer you with rights, warranties, guarantees and remedies relating to the provision of Services by us to you which cannot be excluded, restricted or modified (Statutory Rights). Our liability is governed solely by the UK Consumer Rights Act and these Terms.
9.2 Services: If you are a consumer as defined in the UK Consumer Rights Act, the following applies to you: We guarantee that the Services we supply to you are rendered with due care and skill; fit for the purpose that we advertise, or that you have told us you are acquiring the Services for or for a result which you have told us you wish the Services to achieve, unless we consider and disclose that this purpose is not achievable; and will be supplied within a reasonable time. To the extent we are unable to exclude liability; our total liability for loss or damage you suffer or incur from our Services is limited to us re-supplying the Services to you, or, at our option, us refunding to you the amount you have paid us for the Services to which your claim relates.
9.3 Delay: Where the provision of Services depends on your information or response, we have no liability for a failure to perform the Services in this estimated period, which is affected by your delay in response, incomplete or incorrect information.
9.4 Warranties: To the extent permitted by law, we exclude all express and implied warranties, and all material and work is provided to you without warranties of any kind, either express or implied. We expressly disclaim all warranties including but not limited to implied warranties of merchantability and fitness for a particular purpose.
9.5 Liability: To the extent permitted by law, we exclude all express or implied representations, conditions, guarantees and terms relating to the Services and this agreement, except those set out in this agreement, including but not limited to:
(a) implied or express guarantees, representations or conditions of any kind, which are not stated in the Terms;
(b) our Services being unavailable; and
(c) any loss, damage, costs including legal costs, or expense whether direct, indirect, incidental, special, consequential and/or incidental, including loss of profits, revenue, production, opportunity, access to markets, goodwill, reputation, use or any indirect, remote, abnormal or unforeseeable loss, or any loss or damage relating to business interruption, or otherwise, suffered by you or claims made against you, arising out of or in connection with the inability to access or use the Services, and the late supply of Services, even if we were expressly advised of the likelihood of such loss or damage.
9.6 Limitation: Our total liability arising out of or in connection with our Services, however arising, including under contract, tort, including negligence, in equity, under statute or otherwise, will not exceed the total fees paid by you to us in the twelve (12) month period prior to the event giving rise to the liability, or one hundred pounds (GBP£100) if no such payments have been made, as applicable.
9.7 This clause will survive termination of these Terms.
10. Indemnity
10.1 You are liable for and agree to indemnify, defend and hold us harmless for and against any and all claims, liabilities, suits, actions and expenses, including costs of litigation and reasonable legal costs, resulting directly or indirectly from:
(a) any information that is not accurate, up to date or complete or is misleading or a misrepresentation;
(b) any breach of these Terms; and
(c) any misuse of the Services from or by you, your employees, contractors or agents.
10.2 You agree to co-operate with us (at your own expense) in the handling of disputes, complaints, investigations or litigation that arise as a result of your use of our Services including but not limited to disputes, complaints, investigations or litigation that arises out of or relates to incorrect information you have given us.
10.3 The obligations under this clause will survive termination of these Terms.
11. General
11.1 Privacy: We agree to comply with the legal requirements of the UK General Data Protection Regulation (UK GDPR) and any other applicable legislation or privacy guidelines.
11.2 Publicity: You consent to us using advertising or publicly announcing that we have undertaken work for you.
11.3 Email: You acknowledge that we are able to send electronic mail to you and receive electronic mail from you. You release us from any claim you may have as a result of any unauthorised copying, recording, reading or interference with that document or information after transmission, for any delay or non-delivery of any document or information and for any damage caused to your system or any files by a transfer.
11.4 Tax: If and when applicable, tax payable on our Services will be set out on our Invoices. By accepting these Terms you agree to pay us an amount equivalent to the any taxes imposed on these charges in accordance with the UK tax laws.
11.5 Relationship of parties: The Terms are not intended to create a relationship between the parties of partnership, joint venture, or employer–employee.
11.6 Severance: If any provision (or part of it) of the Terms is held to be unenforceable or invalid in any jurisdiction, then it will be interpreted as narrowly as necessary to allow it to be enforceable or valid under UK law. If a provision (or part of it) of these Terms cannot be interpreted as narrowly as necessary to allow it to be enforceable or valid, then the provision (or part of it) must be severed from these Terms and the remaining provisions (and remaining part of the provision) of the Terms are valid and enforceable.
11.7 Force Majeure: We will not be liable for any delay or failure to perform our obligations under the Terms if such delay is due to any circumstance beyond our reasonable control. If we are delayed from performing our obligations due to such a circumstance for a period of at least 2 months, we may terminate our agreement with you by giving you 5 days’ notice in writing.
11.8 Notice: Any notice required or permitted to be given by either party to the other under these conditions will be in writing. For you, the notice should be sent to the address you have provided on our Website. For us, the notice should be sent to our designated email address, which will be provided to you. Any notice may be sent by email, and notice will be deemed to have been served at the time of transmission.
11.9 Jurisdiction & Applicable Law: These terms are governed by the laws of the United Kingdom. Each party irrevocably and unconditionally submits to the exclusive jurisdiction of the courts operating in the United Kingdom.
11.10 Entire Agreement: These Terms and any document expressly referred to in them represent the entire agreement between you and us and supersede any prior agreement, understanding or arrangement between you and us, whether oral or in writing.
12. Definitions
12.1 Business Day means a day that is not a Saturday, a Sunday or a public holiday in the United Kingdom.
12.2 Confidential Information includes confidential information about the business, structure, programs, processes, methods, operating procedures, activities, products and services, trade secrets, know how, financial, accounting, marketing and technical information, customer and supplier lists (including prospective customer and supplier information), ideas, concepts, know-how, Intellectual Property, technology, and other information whether or not such information is reduced to a tangible form or marked in writing as “confidential”.
12.3 Intellectual Property includes any and all intellectual and industrial property rights throughout the world, whether subsisting now or in the future and includes all copyright and analogous rights, all rights in relation to inventions (including patent rights), registered and unregistered trademarks, designs (whether or not registered or registrable), circuit layouts, trade names, trade secrets, business names, company names or internet domain names.
13. Website
CourseWizz Ltd
Date: 31st July 2023